Be it enacted by the Senate and House of Representatives in General Court assembled, and by the authority of the same as follows:
SECTION 1. As used in this act, the following words shall have the following meanings unless the context clearly requires otherwise:-
“Developer”, the private entity selected to build, maintain and operate a new Parker’s River Marina.
“Development agreement”, the agreement entered into between the developer and the town, pursuant to clause (a) of section 4.
“Project”, the study, planning, design, construction, reconstruction, operation and maintenance of a new Parker’s River Marina in the town for public use in accordance with the terms of the development agreement.
“Town”, the town of Yarmouth.
SECTION 2. Notwithstanding chapters 30, 30B and 149 of the General Laws or any other general or special law to the contrary, the chief procurement officer of the town or his designee may solicit proposals for and, in conjunction with the board of selectmen, may negotiate and authorize the town to enter into a development agreement with a developer to undertake, as appropriate, all or a portion of the project using, in whole or in part, private sources of financing.
SECTION 3. (a) The chief procurement officer or his designee shall develop and publicly advertise a request for qualifications setting forth criteria for prequalification of developers, including minimum levels of experience, financial capability, bonding capacity and such other criteria as may be deemed appropriate by the board of selectmen. The chief procurement officer or his designee, may consult with legal, financial, technical or other experts in the prequalification of developers. The chief procurement officer shall also consult with the board of selectmen in the development of a request for qualifications and with respect to the financial capacity of the respondents to such request for qualifications before determining which respondents are qualified. The chief procurement officer shall select a minimum of 3 developers who have been determined to be the most qualified, based on their abilities to finance and construct the project.
(b) The chief procurement officer or his designee shall develop and publicly advertise a request for proposals setting forth criteria of the qualified developers to undertake the project. The chief procurement officer or his designee may consult with legal, financial, technical and other experts within and outside government in the development of the request for proposals, the selection of a developer and the negotiation of a development agreement. The chief procurement officer or his designee shall not select a developer in accordance with this section without the written concurrence of the board of selectmen that the selected developer and its proposal have appropriate financial characteristics and provisions.
(c) The chief procurement officer or his designee shall, within 30 days after the designation of the selected qualified developers, furnish each qualified developer, as determined in subsection (a), with a request for proposals setting forth the minimum criteria for the project. Each such developer may then submit to the town, on or before the time and date specified in the request for proposals, a proposal in the format specified by the chief procurement officer or his designee. The chief procurement officer or his designee may waive any informalities in such proposals and reject any proposal if, in his sole discretion, such a rejection would be in the public interest. All proposals shall be reviewed in private and no proposal or any information contained therein shall be released to a third party other than as specified therein before the execution of the development agreement in accordance with this section and no such proposal shall be a public record until such development agreement is executed.
(d) Each proposal shall be evaluated by criteria determined by the chief procurement officer or his designee, in conjunction with the board of selectmen, and set forth in the request for proposals including, but not limited to, the proposed cost of the project and the financial benefit to the town, the reputation, industry experience and financial capacity of the developer, the time schedule for completion of the project, local citizen and government concerns, environmental concerns relative to the project, benefits to the public, the developer’s ability to ensure labor harmony during the length of the project and such other criteria as deemed appropriate. The chief procurement officer or his designee may request oral presentations by such developers as he deems necessary for understanding, clarifying and improving the terms contained in the proposals. An oral presentation shall include a written component, including minutes of the meeting at which the presentation took place, which shall be made public after the execution of the development agreement.
(e) The chief procurement officer shall select the developer that he determines best meets the selection criteria for the benefit of the town. If the chief procurement officer selects a developer that did not submit the proposal offering the highest overall return to the town, the chief procurement officer shall explain the reason for the selection in writing to the board of selectmen before the execution of the agreement.
SECTION 4. The board of selectmen, by a majority vote, may enter into a binding development agreement with the selected developer, subject to such terms and conditions as the board of selectmen shall determine to be in the best interests of the town, and the development agreement shall:
(1) provide for construction of the project;
(2) specify a construction schedule with project milestones and an enforceable project completion date, subject to delays beyond the control of the developer;
(3) specify the cost of the project, as an aggregate total and separated into cost for each identified project segment, with maintenance costs annualized and separated from the cost of construction;
(4) provide for a lease of the facility to the developer for a term not to exceed 40 years, with an option for renewal or extension of operation and maintenance services for 1 additional term not exceeding 10 years upon the completion and final acceptance of the project, but the developer shall retain the primary responsibility for all reconstruction, capital maintenance and operational maintenance work, if any, to be performed during the lease period; provided, however, that if the developer proposes that a third party perform any of the work on its behalf, then the third party shall be approved in advance by the chief procurement officer;
(5) establish a schedule for annualized, periodic or other payments by the developer to the town, including establishment of a fund to assure the adequacy of maintenance expenditures; provided, however, that all payments shall be made in accordance with obligations established in the development agreement;
(6) describe the procedures to be utilized in the completion of construction of the project;
(7) outline the responsibilities of the town and the developer in obtaining any remaining environmental permits or approvals;
(8) require that the developer to secure and maintain bonding and liability insurance coverage in amounts appropriate to protect the project’s viability in accordance with section 7;
(9) describe the method of financing for the project, including the developer’s plans for issuing bonds on a tax-exempt basis;
(10) set forth the commitments of the town necessary to secure the project’s financing consistent with subsection (b) of section 10;
(11) set forth the guarantee of performance and security to be provided by the developer;
(12) specify the claims process to be utilized in the event of unforeseen circumstances during project design or construction and provide for the reimbursement to the developer for reasonable costs and expenses incurred in developing the design of the project and the construction costs estimate and in the financing of the project should the town, for any reason, decide to terminate the agreement;
(13) clarify the responsibilities of the town and the developer in responding to hazardous materials on the developmental site;
(14) designate responsibility for operation and maintenance of the facility before, during and after project construction; and
(15) provide that the town’s construction inspections shall be conducted by personnel employed directly and on a full-time basis by the town.
SECTION 5. The chief procurement officer shall obtain town meeting vote approval if the elected developer plans to issue non-tax exempt bonds.
SECTION 6. Agreements with the developer shall contain minority and women business enterprise or disadvantaged business enterprise goals and minority and women work force goals as specified by the town in accordance with state and federal law.
SECTION 7. An agreement with a developer shall require the developer’s prime contractor to obtain a labor and material payment bond in accordance with section 29 of chapter 149 of the General Laws to cover all construction, reconstruction or maintenance, including capital maintenance, work of the project and shall require the payment of prevailing wages for labor performed on the project in accordance with sections 26 to 27H, inclusive, of said chapter 149.
SECTION 8. Notwithstanding chapters 7, 30, and 149 of the General Laws or any other general or special law to the contrary regarding procurement practices, the developer shall, in its sole discretion and in accordance with its own procurement practices and sound business judgment, determine the qualifications and selection of its own consultants, engineers, designers, architects, lawyers, contractors, investment bankers, materials suppliers and other persons or entities employed in connection with the project. The developer shall remain subject to all applicable antidiscrimination laws including, but not limited to, chapter 151B of the General Laws.
SECTION 9. (a) The plans and specifications for the project shall be approved by the board of selectmen.
(b) The development agreement shall provide that, upon return of operation and control of the facility to the town, the facility shall be in good repair in accordance with appropriate standards as shall be set forth in writing and incorporated by reference in the development agreement prior to the commencement of the construction of the project. The town shall also set forth the guidelines and standards to which the developer shall periodically maintain the facility and shall require the developer to repair the facility if the facility is found not to be in accordance with such maintenance standards, as shall be indicated by the town in writing.
(c) The town may exercise, on its own behalf and on behalf of the developer, any power possessed by it to facilitate the development, construction, financing, operation and maintenance of the facility. For the purpose of facilitating the project or to assist the developer in the financing, development, construction, maintenance or operation of the facility, the development agreement may include provisions for the town (i) to lease the facility to the developer or back from the developer or both; (ii) to exercise the power of eminent domain; (iii) to grant development rights and opportunities to the developer and third parties; (iv) to grant necessary easements and rights of access to the developer and third parties; (v) to issue permits and other authorizations; (vi) to provide remedies in the event of default of either of the parties; (vii) to grant contractual and real property rights to the developer and third parties; and (viii) to exercise any other power deemed necessary by the parties. Any person damaged in his property by the exercise of any of the powers granted in this section may recover damages under chapter 79 of the General Laws against the town with respect to those powers exercised by the town. Nothing in this section shall be construed in a manner that would allow the town or the developer to override any local zoning or land use law, ordinance or regulation.
SECTION 10. (a) In order to facilitate project refinancing, the selected developer may form a special purpose entity and the town may enter into agreements with such entity to effectuate the purposes of this section.
(b) Revenue bonds, interim receipts, temporary bonds, revenue refunding bonds or other types of indebtedness necessary to finance the construction, maintenance and operation of the facility shall not be deemed to constitute a debt of the town or any political subdivision thereof. All bonds and interim receipts shall contain on the face thereof a statement to the effect that neither the town nor any political subdivision thereof shall be obligated to pay the same or the interest thereon except from revenues generated by the facility, or from other federal, state or local resources specifically made available therefor, and that neither the faith and credit nor the taxing power of the town or any political subdivision thereof is pledged to the payment of the principal of or interest on the bonds and interim receipts.
SECTION 11. (a) While the developer has operation and control of the facility pursuant to a development agreement, the developer shall be liable to the same extent and with the same limitations as would be the town to any person sustaining bodily injury or damage to his property by reason of a defect or want of repair therein or thereupon as though the facility were a facility operated by the town and the developer shall be liable for the death of a person caused by such defect or want of repair to the same extent and with the same limitations as would be the town under chapter 258 of the General Laws. The town shall not be liable for injury, damage or death sustained by any person due to defect or want of repair therein or thereupon sustained during the operation of the facility by the developer. Any notice of such injury, damage or death required by law shall be given to the registered agent of the developer and to the town but claims instituted pursuant to section 4 of said chapter 258 shall be presented to the town. Upon receipt by the town of any such notice, the town shall promptly notify such registered agent of the notice and shall promptly notify the person giving notice of name and address of the registered agent.
(b) While the developer has operation and control of the facility pursuant to a development agreement, the developer shall be liable to the same extent and with the same limitations as would be the town in accordance with chapter 258 of the General Laws, as if the facility were a facility operated by the town. The town shall not be liable for injury, damage or death sustained by a person during the operation of the facility by the developer or for any injury, damage or death caused by the negligence of the developer. Any notice of such injury, damage or death required by law shall be given to the registered agent of the developer and to the town but claims instituted pursuant to section 4 of said chapter 258 shall be presented to the town. Upon receipt by the town of any such notice, the town shall promptly notify such registered agent of the notice and shall promptly notify the person giving notice of the name and address of the registered agent.
SECTION 12. Nothing in this act or any action taken or contract or agreement entered into pursuant to this act shall change or alter any contract or agreement between the town and any public entity which is in force and effect on the effective date of this act or impose any additional costs or obligations on the town or any such public entity.SECTION 13. This act shall take effect upon its passage.
Approved August 10, 2010